Terms of Service

These terms cover this website and the offers described on it. The binding document for any engagement is the signed proposal and contract with YIB Global Technology Services LLP. Where a signed contract and this page disagree, the contract governs.

Who you are contracting with

WebXLR8 is a trading brand. The contracting entity is YIB Global Technology Services LLP, a limited liability partnership registered in Ernakulam, Kerala, India, GSTIN 32AADFY6703B1ZM.

Pricing

The The 30-Day Pilot Build is USD 5,000. That is the published price in every market, and it is the current launch rate, reviewed periodically. Prices quoted on this site are exclusive of any applicable taxes.

BuildXLR8 is quoted per build across three tiers: Focused, up to $20,000; Operations, up to $50,000; Full Platform, above $50,000. Final scope and price are confirmed in a written proposal after scoping. BuildXLR8 Assurance is priced per build and quoted alongside it.

Payment

The 30-Day Pilot Build: 50% at kickoff, 50% on written acceptance of the working demo. Go live and the codebase handover are withheld until the balance clears.

Paid one 30-day milestone at a time, invoiced at each kickoff. We never start a milestone that has not been paid, and you never pay more than the current month in advance.

The Signed Checklist Guarantee

Nothing deploys until every item on the checklist we both signed passes. If the delivered software does not clear the signed acceptance checklist, we continue work at no further charge until it does. This is a completion guarantee and not a cash refund.

On-time terms. The Pilot is built in 30 days. Miss that date for reasons that are solely our fault, past a two week grace, and we discount 10% for every further week late, capped at 50%.

It covers delays on our side only, not a missed access handover, an absent approver, or a feedback window that went unanswered. Scopes containing a third-party integration carry no timeline commitment, because a third party review cycle is not ours to control.

BuildXLR8 guarantees

The Walk-Away Guarantee. Stop after any 30-day cycle. No cancellation fee, no penalty, no exit conversation.

The Acceptance Guarantee. Every milestone passes written acceptance criteria before it is signed off. The next milestone is not billed and not started until it does.

The On-Time Guarantee. Each 30-day milestone ships on its committed date. Miss it for reasons within our control and that milestone is discounted 5% at week two, and a further 5% the week after, capped at 10%. The discount is credited on your next invoice, or refunded if the next milestone is smaller than the credit. Delays on our side only. A missed feedback window or a held-up access request on your side does not trigger it.

The No-Deprioritisation Guarantee. Your build is never paused or slowed to make room for a bigger client. If we ever pull people off your build and a date slips, the On-Time Guarantee applies.

The total discount on any single milestone is capped at 25%.

What we need from you

Every guarantee above assumes a named, empowered approver responding within the agreed window, and timely access to the systems being replaced or integrated. Delays caused by a missed feedback window, an unavailable approver, or withheld access do not trigger any discount, and extend the delivery date by the length of the delay.

If an engagement goes unresponsive beyond an agreed window it is parked, and re-activation carries a re-mobilisation fee set out in the contract.

Ownership

You own the code we write for you. It is transferred to your systems as each milestone completes and is paid for. Third-party components remain under their own licences, and pre-existing tooling of ours remains ours, licensed to you for use within the delivered system.

Scope and integrations

A scope that includes a third-party integration carries no timeline commitment for that portion, because third-party review and approval cycles are outside our control. Integrations are timed and priced separately from the 30 day promise.

Confidentiality

We treat what you show us during scoping and delivery as confidential and will sign an NDA on request. We name clients publicly only with written permission, and we do not attach performance claims to a named client at all.

Liability

Our aggregate liability under any engagement is limited to the fees paid for that engagement. We are not liable for indirect or consequential loss. Nothing here limits liability that cannot be limited by law.

Website content

Content on this site is provided for information. It is not a binding offer, and figures described here can change. No performance, ROI, or time-saving outcome is warranted anywhere on this site, and none is claimed.

Governing law

These terms and any engagement are governed by the laws of India, with the courts of Ernakulam, Kerala having jurisdiction, unless a signed contract states otherwise.